Request for Proposals

Camden Rockport Elementary School (CRES) Phase One Interior Painting Project

Issuing Agency:
MSAD 28
22 Knowlton St
Rockport ME 04856
Contact Info:
Christopher D. Fanelli: Director of Facilities and Transportation
Phone: 207-236-7340
E-mail: christopher.fanelli@fivetowns.net
Evaluation Committee:
Christopher D. Fanelli. Director of Facilities and Transportation
Pete Orne, Director of Finance
Chris Walker-Spencer, Principal
Timeline:
Date RFP Issued: 11/30/23
Dates Advertised: 11/30/23 – 12/29/23
Contractor Site Visit: 12/11/23
Questions accepted until: 1/4/2024
Answers in writing: 1/4/24 10:00 am
Proposals Due: 1/5/24 10:00 a.m.
Proposals Opened: 1/5/24 11:00 a.m.
Proposals Evaluated: 1/5/24
Possible Award of Contract: 1/8/24
Start of Construction: 6/24/24
Installation Substantial Completion By: 8/30/24
Installation Final Completion By: 8/30/24



I. Project Description
MSAD 28 requests proposals for the following project, Camden Rockport Elementary School (CRES) Phase One Interior Painting Project as part of the overall goal of repainting the main entryway, main lobby, hallway, and existing stairwell.

II. Description of RFP Process; Selection Criteria
Interested contractors must adhere to the timeline identified in this request. In the event that alterations to the timeline become necessary, all contractors that have submitted their intention to submit proposals will be notified of the changes and an addendum will be added to this document.
The School District will subjectively evaluate proposals based upon the following criteria:
1. How well the proposal meets the needs of the School District;
2. Cost effectiveness;
3. Experience with similar jobs
4. Financial capacity (Maine statute requires public projects in excess of $125,000 to be
secured by payment and performance bonds)
5. References.
Proposals will be good for at least 90 days after they are submitted. The School District
reserves the right to reject any or all proposals, to exercise its judgment in evaluating
proposals, to negotiate with one or more contractors submitting proposals and to request clarifications and/or demonstrations.

Request for Proposals

Camden Hills Regional High School (CHRHS) Tennis Court Resurfacing Project

Issuing Agency:
Five Town CSD
22 Knowlton St
Rockport ME 04856
Contact Info:
Christopher D. Fanelli: Director of Facilities and Transportation
Phone: 207-236-7340
E-mail: christopher.fanelli@fivetowns.net
Evaluation Committee:
Christopher D. Fanelli. Director of Facilities and Transportation
Pete Orne, Director of Finance
Jen Curtis, Principal
Timeline:
Date RFP Issued: 11/30/23
Dates Advertised: 11/30/23 – 12/29/23
Contractor Site Visit: 12/12/23
Questions accepted until: 1/4/2024
Answers in writing: 1/4/24 10:00 am
Proposals Due: 1/5/24 10:00 a.m.
Proposals Opened: 1/5/24 11:00 a.m.
Proposals Evaluated: 1/5/24
Possible Award of Contract: 1/8/24
Start of Construction: TBD
Installation Substantial Completion By: 9/1/25
Installation Final Completion By: 9/1/25



I. Project Description
Five Town CSD requests proposals for the following project, Camden Hills Regional High School (CHRHS) Tennis Court Resurfacing Project as part of the overall goal of completing the High School’s almost 20 year old Tennis Court & Perimeter Fence.

II. Description of RFP Process; Selection Criteria
Interested contractors must adhere to the timeline identified in this request. In the event that alterations to the timeline become necessary, all contractors that have submitted their intention to submit proposals will be notified of the changes and an addendum will be added to this document.
The School District will subjectively evaluate proposals based upon the following criteria:
1. How well the proposal meets the needs of the School District;
2. Cost effectiveness;
3. Experience with similar jobs
4. Financial capacity (Maine statute requires public projects in excess of $125,000 to be
secured by payment and performance bonds)
5. References.
Proposals will be good for at least 90 days after they are submitted. The School District
reserves the right to reject any or all proposals, to exercise its judgment in evaluating
proposals, to negotiate with one or more contractors submitting proposals and to request clarifications and/or demonstrations.

Request for Proposals

Camden Hills Regional High School (CHRHS) Phase One Interior Painting Project

Issuing Agency:
Five Town CSD
22 Knowlton St
Rockport ME 04856
Contact Info:
Christopher D. Fanelli: Director of Facilities and Transportation
Phone: 207-236-7340
E-mail: christopher.fanelli@fivetowns.net
Evaluation Committee:
Christopher D. Fanelli. Director of Facilities and Transportation
Pete Orne, Director of Finance
Jen Curtis, Principal
Timeline:
Date RFP Issued: 11/30/23
Dates Advertised: 11/30/23 – 12/29/23
Contractor Site Visit: 12/11/23
Questions accepted until: 1/4/2024
Answers in writing: 1/4/24 10:00 am
Proposals Due: 1/5/24 10:00 a.m.
Proposals Opened: 1/5/24 11:00 a.m.
Proposals Evaluated: 1/5/24
Possible Award of Contract: 1/8/24
Start of Construction: 6/24/24
Installation Substantial Completion By: 8/30/24
Installation Final Completion By: 8/30/24



I. Project Description
Five Town CSD requests proposals for the following project, Camden Hills Regional High School (CHRHS) Phase One Interior Painting Project as part of the overall goal of repainting the main entryway, main lobby, hallway, and existing stairwell.

II. Description of RFP Process; Selection Criteria
Interested contractors must adhere to the timeline identified in this request. In the event that alterations to the timeline become necessary, all contractors that have submitted their intention to submit proposals will be notified of the changes and an addendum will be added to this document.
The School District will subjectively evaluate proposals based upon the following criteria:
1. How well the proposal meets the needs of the School District;
2. Cost effectiveness;
3. Experience with similar jobs
4. Financial capacity (Maine statute requires public projects in excess of $125,000 to be
secured by payment and performance bonds)
5. References.
Proposals will be good for at least 90 days after they are submitted. The School District
reserves the right to reject any or all proposals, to exercise its judgment in evaluating
proposals, to negotiate with one or more contractors submitting proposals and to request clarifications and/or demonstrations.

Request for Proposals

Camden Hills Regional High School (CHRHS) Football Goal Post Project

Issuing Agency:
Five Town CSD
22 Knowlton St
Rockport ME 04856
Contact Info:
Christopher D. Fanelli: Director of Facilities and Transportation
Phone: 207-236-7340
E-mail: christopher.fanelli@fivetowns.net
Evaluation Committee:
Christopher D. Fanelli. Director of Facilities and Transportation
Pete Orne, Director of Finance
Jen Curtis, Principal
Timeline:
Date RFP Issued: 11/30/23
Dates Advertised: 11/30/23 – 12/29/23
Contractor Site Visit: 12/14/23
Questions accepted until: 1/4/2024
Answers in writing: 1/4/24 10:00 am
Proposals Due: 1/5/24 10:00 a.m.
Proposals Opened: 1/5/24 11:00 a.m.
Proposals Evaluated: 1/5/24
Possible Award of Contract: 1/8/24
Start of Construction: TBD
Installation Substantial Completion By: 9/1/25
Installation Final Completion By: 9/1/25



I. Project Description
Five Town CSD requests proposals for the following project, Camden Hills Regional High School (CHRHS) Football Goal Post Project as part of the overall goal of removing existing two goal posts and installing new replacements.

II. Description of RFP Process; Selection Criteria
Interested contractors must adhere to the timeline identified in this request. In the event that alterations to the timeline become necessary, all contractors that have submitted their intention to submit proposals will be notified of the changes and an addendum will be added to this document.
The School District will subjectively evaluate proposals based upon the following criteria:
1. How well the proposal meets the needs of the School District;
2. Cost effectiveness;
3. Experience with similar jobs
4. Financial capacity (Maine statute requires public projects in excess of $125,000 to be
secured by payment and performance bonds)
5. References.
Proposals will be good for at least 90 days after they are submitted. The School District
reserves the right to reject any or all proposals, to exercise its judgment in evaluating
proposals, to negotiate with one or more contractors submitting proposals and to request clarifications and/or demonstrations.

Town of Warren is accepting
applications for a full-time or
seasonal plow/truck driver/
laborer. Applications may be
picked up at the Warren Town
Office, Monday-Friday 9am to 4pm
or can be printed from
www.warrenmaine.org. Position
will be open until the right
candidate is hired.

Maritime Energy is seeking a Journeyman Plumber to join our team at the Montville/So China office. Master Plumber and Oil and LP licenses a plus. A clean driving record is a must. Maritime Energy offers highly competitive weekly pay for the right talent and full time benefits including health, dental, and life insurance, an employer matched 401(k), paid PTO time, paid holidays, and employee purchasing discounts on home heating fuel products. If you are interested in joining Maritime Energy’s service team please send resume and references to: Jeff Snow, HR Manager, Maritime Energy, PO Box 485, Rockland, ME 04841. jeffsnow@maritimeenergy.com. (207) 596-0986 ext 119.

The difference is We Care.....about our employees, our customers and our community.
Due to growth, Maritime Energy is seeking to add experienced full time Oil Burner and Propane Technicians to our team. Location opportunities include the Rockland office, the Montville and So China offices. The position requires a Master or Journeyman’s license with experience in oil burner service/installation, LP service/installation, and the commitment to provide superior customer service. Upon a conditional job offer, a pre-employment physical screening will be required. Competitive weekly pay. Benefits include health, dental, vision, STD and life insurance, an employer matched 401(k), paid PTO time, paid holidays, and employee purchasing discounts on home heating fuel products. If you are interested in joining Maritime Energy’s service team please send a resume and references to: Jeff Snow, Human Resources Manager, Maritime Energy, PO Box 485, Rockland, ME 04841, jeffsnow@maritimeenergy.com or call (207) 596-0986 ext 119.

Beachfront enclave accommodating
8 guests in 2 homes. Available
July 2024. Text: 2072304223

Shorty’s Clean Up & Debris
Removal Let us help you with
declutter and get rid of junk.
We want to help you get rid of
your junk and declutter your
life for you. We do everything
from house trash pick ups on up
to yard/construction debris
removal and demolition.
Commercial properties and
residential properties. Fully
insured and licensed
shortyjunkremovel@gmail.com
207-380-7657